Loading...
Serving Delano, CA and surrounding areas. (661) 553-7102
Effective Date: January 1, 2026
By accessing or using the website located at delanodeckandfence.com (the "Site"), or by engaging Superior Delano Deck & Fence ("we," "us," or "our") for any services, you agree to be bound by these Terms and Conditions. If you do not agree, please do not use the Site or engage our services.
These Terms apply to all visitors to the Site and to all customers who hire us for deck building, fence installation, or related outdoor construction services in Delano, CA and surrounding areas.
Superior Delano Deck & Fence provides residential deck construction, fence installation, patio covers, pergola installation, and related outdoor structure services to homeowners in Delano and surrounding communities in Kern County, California. The specific scope of work for any project is defined in the written proposal and contract provided to the customer before work begins.
Information on this Site about our services is provided for general informational purposes only. It is not a binding offer or contract. No service agreement exists until a written proposal is signed by both parties.
All estimates provided by Superior Delano Deck & Fence - whether given verbally, by email, or in writing - are estimates only until a formal written contract is signed by both parties. Written contracts contain the final agreed price and scope of work.
The price stated in a signed contract is firm for the scope of work described in that contract. Changes to the scope of work requested by the customer after the contract is signed may result in additional charges. Any such changes will be documented in a written change order signed by both parties before additional work is performed.
We reserve the right to revise estimates if site conditions discovered during the project differ materially from what was observable at the time of the initial estimate. We will notify you promptly in writing before proceeding with work that would affect the contract price.
Project start dates are scheduled based on permit approval timelines, material availability, and crew scheduling. We will provide you with an estimated start date at the time of contract signing and will keep you informed of any changes.
If you need to cancel a signed contract, please notify us in writing as soon as possible. Cancellation terms, including any applicable deposits or fees for work already performed or materials already ordered, are specified in your written contract. If no cancellation terms are stated in the contract, any costs already incurred by us for your project - including permit fees and materials ordered - may be charged to you at cost.
We reserve the right to reschedule work due to weather conditions, permit delays, or circumstances beyond our control. We will communicate any rescheduling to you promptly.
Payment terms are specified in your written contract. A deposit is typically required before work begins, with the balance due upon project completion and final walkthrough. Specific amounts and timing are outlined in your individual contract.
Payments not received by the due date stated in the contract may be subject to a late fee. If payment is not received within 30 days of the due date, we reserve the right to place a mechanic's lien on the property in accordance with California law.
Under California law, any contractor who receives a deposit from you must comply with regulations governing contractor deposits and progress payments. A copy of your rights as a homeowner under California contractor law is available from the California Contractors State License Board at cslb.ca.gov.
Superior Delano Deck & Fence is responsible for obtaining required building permits for projects where a permit is legally required. The cost of permit fees is included in or added to the written contract. Project timelines are subject to the permit review process, which is controlled by the relevant municipal authority and outside our control.
The customer is responsible for obtaining any required homeowners association (HOA) approvals before work begins. We are not responsible for delays or modifications required due to HOA rules that the customer did not disclose or was unaware of at the time of contract signing.
Any workmanship warranty provided by Superior Delano Deck & Fence is stated in your written contract. Where no specific warranty period is stated, we warrant our workmanship against defects in installation for one year from the date of project completion and final inspection.
Materials and products installed by us are covered by the manufacturer's warranty where one exists. We do not extend or modify manufacturer warranties. Normal wear and tear, damage from weather events, and issues resulting from customer modifications to completed work are not covered by our workmanship warranty.
The Site and its content are provided on an "as is" basis without warranties of any kind. We do not warrant that the Site will be uninterrupted or error-free.
To the fullest extent permitted by applicable law, Superior Delano Deck & Fence shall not be liable for any indirect, incidental, special, or consequential damages arising out of or related to our services or the use of this Site - including loss of use of property, loss of revenue, or costs of substitute services - even if we have been advised of the possibility of such damages.
Our total liability to you for any claim arising out of a service agreement shall not exceed the total amount paid by you to us under that agreement. This limitation applies to the maximum extent permitted by California law.
If a dispute arises between you and Superior Delano Deck & Fence relating to our services, we encourage you to contact us first at projects@delanodeckandfence.com or (661) 553-7102 so we can attempt to resolve it directly. Most issues can be resolved quickly with a direct conversation.
If a dispute cannot be resolved informally, the parties agree to attempt mediation before initiating any formal legal proceeding. Mediation shall take place in Kern County, California, unless both parties agree to a different location.
You may also file a complaint with the California Contractors State License Board (cslb.ca.gov) if you believe we have violated contractor licensing laws.
These Terms and Conditions and any service agreements between you and Superior Delano Deck & Fence are governed by and construed in accordance with the laws of the State of California, without regard to its conflict of law principles. Any legal action arising from these Terms or our services shall be brought in the courts of Kern County, California.
You may use this Site for lawful purposes only. You agree not to use the Site to transmit any harmful, unlawful, or offensive content, or to interfere with the operation of the Site or its servers. We reserve the right to restrict or terminate access to the Site at our discretion.
All content on this Site - including text, images, and design - is owned by or licensed to Superior Delano Deck & Fence and may not be reproduced without our written permission.
We may update these Terms and Conditions at any time. Updated terms will be posted on this page with a revised effective date. Your continued use of the Site or engagement of our services after any changes constitutes your acceptance of the updated terms. We recommend reviewing this page periodically.
If you have questions about these Terms and Conditions, please contact us:
Superior Delano Deck & Fence
1314 10th Ave
Delano, CA 93215
Return to our homepage, learn about us, or contact us with any questions.